一键复制
随着人们法律意识的加强，越来越多的人通过合同来调和民事关系，签订合同能够较为有效的约束违约行为。那么合同应该怎么制定才合适呢？这里我整理了一些优秀的合同范文，希望对大家有所帮助，下面我们就来了解一下吧。
广告合约合同篇一
telephone：
party b: address:
telephone：
according to the provisions of the contract law of the people's republic of china and the relevant laws and regulations, party b accepts the entrustment of the first party and entrustment with the two parties through consultation.
first, entrustment:
two, the way of payment:
1, party a shall pay 40% of the total cost of the contract, namely ____ yuan (rmb) to party b, party b received the money after the start of design.
2. party b shall provide complete design draft. after confirmation by party a, the total amount of the total cost shall be paid.
three. design time:
1, party b shall provide complete design draft in __ working days.
2, party b shall complete the design work of party a company commissioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).
four. the responsibilities and obligations of the two parties:
1, party b shall, according to the requirements of party a to finish the related work on time.
2, party a has the responsibility to fully cooperate with party b to carry out the work stipulated in this contract and provide relevant information according to the needs of party b. party a is responsible for the consequences caused by party a's delay in the required information.
3. party a shall provide complete design information before the start of the design, due to party a's provision of incomplete information and changes in content.
for structural changes, party a shall pay the corresponding cost of design changes.
4. after party b receives the complete design information of party a, it is designed to facilitate the determination of the style of party a, and party b begins to design the first draft after the style is determined.
5, party a has the right to put forward amendments to the works designed by party b. the first draft party a can make a structural modification. after the first draft is determined, the structural modifications should be made. party a shall pay the corresponding cost separately.
6. the consequences of the delay due to the amendment of party a shall be borne by party a.
7, due to the loss caused by post production by party a alone, the loss caused by problems in the design of the product is borne by party b. the legal liability caused by copyright, for the economic disputes shall be borne by party a..
8. during the course of the project, party b is attached to the brand of party a and shall not sign any form of cooperation agreement with the customer in the identity of party b.
five. the agreement on intellectual property rights:
1, party b has the copyright of the works completed by the design. after the settlement of all the fees designed by party a, party b may transfer the copyright of the works to party a.
2. before party a has not paid all the cost of the design, the copyright of the works designed by party b shall be attributed to party b, and party a does not have any right to the work.
3. party a shall have the right to investigate the legal liability of party a if it uses or amends the works designed by party b before the payment is not paid.
six. liability for breach of contract:
1, party a terminates the contract before the completion of the first draft of the design work. the prepaid expenses have no right to request the return. if a party terminates the contract after the completion of the first draft of party b's work, it shall pay the full design fee.
2. if party b terminates the contract without proper reasons, the fees charged shall be returned to party a.
seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. if either party fails to negotiate, any party a and b can submit it to the beijing arbitration commission for arbitration.
eight, the contract is effective from the date of signature by gai zhang and both parties. the contract is two copies in one form. each party has one contract signed by the other party (gai zhang), which has the same legal effect.
nine. if there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. the contents of the supplement and modification are equally valid to this contract.
party a: party b:
(signature seal) (signature seal)
date: date:
地址：
电话：
乙方：地址：
电话：
依据《中华人民共和国合同法》和有关法规的规定，乙方接受甲方的委托，就委托设计事项，双方经协商一致，签订本合同，信守执行：
一、委托事项：
二、付款方式：
1、甲方需在合同签订之时支付总费用的40% ，即____元(人民币)给乙方，乙方收到甲方的款项后开始设计。
2、乙方提供完整的设计稿，甲方确认后,应当即付清总费用的全部余款。
三、设计时间：
1、乙方需在__个工作日内提供比较完整的设计稿。
2、乙方需在_____年__月__日完成甲方公司委托的设计工作 (由甲方原因耽误的时间，完稿时间应顺延)。
四、双方的责任与义务：
1、乙方应按甲方要求按质按量按时完成相关设计工作。
2、甲方有责任全力配合乙方开展本合同所规定的工作，并根据乙方需要提供相关资料。由于甲方提供所需资料延误时间造成的后果，由甲方承担。
3、甲方应在设计开始前提供完整的设计资料，由于甲方提供资料不完整、内容改动而造成的设
计结构改动，甲方须另行支付相应的设计改动费用。
4、乙方收到甲方的完整设计资料后进行部分小样设计以方便甲方确定风格，风格确定后乙方开始进行初稿设计。
5、甲方有权对乙方所设计的作品提出修改意见，初稿甲方可提出一次结构上的修改，初稿确定后的结构修改，甲方须另行支付相应费用。
6、因甲方修改，延误时间造成的后果，由甲方承担。
7、由于后期制作造成的损失由甲方独自承担，由于制作物设计出现问题造成的损失由乙方承担。 因版权、文责所引发的法律责任，经济纠纷由甲方承担。
8、设计项目期间乙方挂靠于甲方品牌之中，不得以乙方身份单独与客户签订任何形式的合作协议。
五、知识产权约定：
1、乙方对设计完成的作品享有著作权。甲方将委托设计的所有费用结算完毕后，乙方可将作品著作权转让给甲方。
2、甲方在未付清所有委托设计费用之前，乙方设计的作品著作权归乙方，甲方对该作品不享有任何权利。
3、甲方在余款未付清之前擅自使用或者修改使用乙方设计的作品而导致的侵权，乙方有权追究其法律责任。
六、违约责任：
1、甲方在设计作品初稿完成前终止合同，其预付的费用无权要求退回；甲方在乙方作品初稿完成后终止合同的，应当支付全额的设计费用。
2、乙方如无正当理由提前终止合同，所收取的费用应当全部退回给甲方。
七、甲乙双方如因履行本合同发生纠纷，应当友好协商解决，协商不成的，甲乙双方任何一方均可向北京仲裁委员会提请仲裁解决。
八、本合同自甲乙双方签字盖章之日起生效，本合同一式两份，双方各持对方签字（盖章）合同一份，具有同等的法律效力。
九、本合同如有未尽事宜，由甲乙双方共同讨论补充或修改。补充和修改的内容与本合同具有同等效力。
甲方： 乙方：
（签字盖章） （签字盖章）
广告合约合同篇二
甲乙双方根据《广告法》及相关法律、法规签订本合同，并共同遵守。
1.甲乙委托乙方于__________年__________月__________日至__________年_____月_____日期间发布第_____期共_____期_____广告，出版日期每月_____日。
2.广告发布媒介为《____________________》杂志。
3.甲方的广告内容和表现形式必须通过乙方的审查，对不符合法律，法规的广告内容和表现形式，乙方应要求甲方做出修改，甲方做出修改前，乙方有权拒绝发布，造成的一切后果由甲方承担。
报纸广告合同范文节选!
4.广告样稿作为合同附件，与本合同一并保存。
5.广告单价_____元，设计费_____元，加急费_____元，其它费用_____元，扣除优惠________元，扣除代理费_________元，刊出次数_____，总计_____元。
6.甲方应在_____年_____月_____日前将广告发布费付给乙方，付款方式_________________。
7.广告客户应提供的证明文件
营业执照以及其他生产，经营资格的证明文件;
对广告中注明认证、专利、获奖、鉴定、注册商标等需提供相应证明文件，对注册统计数据，调查结果等应表明出处并提供相应证明;
确认广告内容真实性及相关的其他证明文件。
注：广告中所用名称必须与营业执照或证明相一致，证明文件需是原件或经原出证部门签章的复制件。
8.甲方提供广告资料
广告内容和表达方式必须符合国家有关广告法规的规定和国家有关出版物的标准规定。
提交软片的客户，务请在出片前将设计稿件传真或寄至乙方，经审核通过后再出片。
定稿后，请打印一份彩样，并同该广告光盘及软件一起于截稿日前寄送乙方。
需要乙方代为制作广告的广告客户，请将广告稿于截稿日前寄至乙方。
除已注册商标外一律使用简化字。
广告截稿日为预刊期前_____天。
9.交付广告费用
广告收费见本合同附件。
本刊实行广告费预付制度，广告费须在广告截稿日之前寄至乙方指定帐号。
广告代理费按国家工商行政管理部门有关规定办理。
甲方____________________乙方____________________
单位名称：________单位名称：________
邮编：__________________邮编：__________________
付款单位：______________收款单位：______________
开户银行：______________开户银行：______________
帐号：__________________帐号：__________________
电话：__________________汇款用途：______________
传真：__________________电话：__________________
单位地址：______________传真：__________________
委托代理人：____________经办人：________________
签订日期：______________
广告合约合同篇三
unit: (hereinafter referred to as party a)
advertisers: (hereinafter referred to as party b)
after friendly consultation between party a and b, in accordance with the principle of mutual benefit and mutual benefit, the following articles are reached on party a's propaganda and planning on party b's entrustment:
article 1: party a entrusts party b to publicity planning project: _________________________
___________________________________________________________
the second article: the principle of propaganda and planning
party b provides the whole process of publicity and planning, including advertising planning and design services, providing reference for party a's market positioning and market area and serving for decision-making.
the third one: the way of agency
party a commissioned party b to complete the whole process of propaganda and planning, and entrusted the plane design, advertising agency and other business, fully responsible for the project publicity and planning.
fourth: the rights and obligations of party a
1. in the agreed period, party b should be required to submit the relevant propaganda and planning scheme, and the party a will assist the organization after the confirmation of the market investigation.
2, it has the right to require party b to provide written opinions and suggestions from the angle of planning within the scope of the commission.
3, party b will be required to provide party a with planning plans and adjustment of propaganda strategies and suggestions.
4, to approve the overall propaganda strategy formulated by party b, and to bear all the costs related to publicity and promotion, advertising and so on.
5, payment shall be paid in accordance with the agreement of the contract with party b for the payment of the publicity and planning fee and on time.
the fifth, the rights and obligations of party b
1, the party shall have the right to pay the publicity and planning fee in accordance with the requirements of the contract.
2, in accordance with the requirements of party a and the different stages of the project progress, put forward the advertising plan, after the approval of party a to organize the implementation.
3, party b provides:
the newspaper project soft article writing; the project, all kinds of exhibitions, promotions, activities planning.
4, bear the claim or other legal liability caused by party b's fault.
sixth: the term of agency
party a entrusts party b publicity planning period is divided into: ______ years ___ month ___ to ______ ___ ___ date month year;
seventh: standard and mode of payment for project publicity and planning
1, publicity planning fees totaling $________ yuan (capital ______________________).
2, after the signing of this contract, party a will pay to party b rmb ____________ whole (capital ___________________________) for payment.
3, after the end of the contract, party a shall pay the balance, namely rmb ____________________ whole (capital ________________________).
the eighth article: liability for breach of contract
1. party a is responsible for all the losses caused by party a's failure to provide relevant license and relevant legal documents and preferential policies for activities.
2. if the party b does not provide the plan of publicity and planning in time because of party b's reasons, party a shall investigate the responsibility or terminate the contract.
3. party a shall have the right to rescind the contract if party a fails to pay party b publicity and planning fees according to the agreement.
4. in the course of cooperation, the other party has the right to require the other party to bear the related economic loss by disclosing the business secrets or providing the relevant information to the third party.
5, any party to terminate the contract without authorization to suspend unilateral breach of contract or shall be borne by the defaulting party, must therefore have caused losses to the observant party and liability for breach of contract.
6, in the execution of this contract, if there is a force majeure factor affecting the execution of the relevant provisions, it shall be settled by the two sides and properly resolved. it is not a breach of contract to terminate the contract or change the relevant provisions of the contract on the basis of the agreement between the two parties.
ninth: annex
1, both parties may supplement the terms of this contract and sign a supplementary agreement in written form. the supplementary agreement has the same legal effect as this contract.
2. the annexes of this contract are all valid parts of the contract and have the same effect.
3. all matters not specified in this contract and its annexes and supplementary agreements are carried out in accordance with the relevant laws, regulations and regulations of the people's republic of china.
4. the contract is two copies, each party and party b has one copy, all with the same legal effect.
5. in the event of a dispute in the performance of this contract, the parties shall settle the dispute by negotiation, negotiation or adjustment, and the parties agree to be arbitrated by the arbitration commission.
6. the contract will terminate naturally after the expiration of the contract. if the two parties renew the contract, they shall make a written opinion to the other party seven days before the expiration of the contract.
7. this contract shall come into force on the date of signature or seal of the representatives of the two parties.
party a: party b:
representative: (signature) representative: (signature)
date: day and date: day and day
单 位：（下简称甲方）
广告商：（下简称乙方）
甲、乙双方经友好协商，本着互惠互利的原则，就甲方委托乙方的宣传策划事宜，达成如下条款：
第一条：甲方委托乙方宣传策划的项目：_________________________
___________________________________________________________
第二条：宣传策划原则
乙方按甲方规定，提供全程宣传策划包括广告策划与设计的服务，为甲方市场定位及市场区域提供参改依据，为决策服务。
第三条：代理方式
甲方委托乙方全权全程宣传策划，并委托平面设计、广告代理等业务，全面负责本次项目的宣传策划工作。
第四条：甲方的权利和义务
1、在约定期限内要求乙方提交有关宣传策划方案，从市场调查依据确认后再由甲方协助组织实施。
2、有权要求乙方在委托范围内从策划角度提供书面意见和建议。
3、要求乙方向甲方提供策划方案及调整宣传策略和建议。
4、批准乙方制订的整体宣传策略，承担有关宣传推广、广告等所需的各项费用。
5、按合同约定与乙方结算宣传策划费并按时支付。
第五条、乙方的权利和义务
1、有权按照合同要求甲方支付宣传策划费。
2、负责根据甲方要求和项目进度的不同阶段，提报广告计划，经甲方认可后组织实施。
3、乙方提供：
⑴、项目报纸软性文章撰写；⑵、项目各种展销、促销、优惠活动的策划。
4、承担因乙方过错造成的索赔或其他法律责任。
第六条：代理期限
甲方委托乙方宣传策划期限分为： ______年___月___日至______年___月___日止；
第七条：项目宣传策划费的给付标准和方式
1、宣传策划费共计￥________元（大写______________________）。
2、本合同签订后，甲方即向乙方支付人民币￥____________整（大写___________________________）为预付款。
3、活动结束后，甲方向乙方支付合同余款，即人民币￥____________________整（大写________________________）.
第八条：违约责任
1、因甲方未提供有关许可证及相关法律文件资料、活动优惠政策而造成损失的，则甲方承担全部责任。
2、如因乙方原因，不及时提供宣传策划方案，甲方追究责任或终止合同。
3、甲方如未按照双方约定支付给乙方宣传策划费，乙方有权解除合同。
4、在合作过程中任何一方泄露商业秘密或将有关资料提供给第三人的，另一方有权要求对方承担相关经济损失。
5、任何一方单方擅自中止合同或解除合同均属违约行为，需由违约方承担因此给守约方造成的相关损失和违约责任。
6、本合同执行过程中，如有因不可抗力因素影响有关条款之执行的，应由双方协商，妥善解决，在双方达成一致意见的基础上而中止合同或改变合同的有关条款的不视为违约。
第九条：附则
1、双方可对本合同的条款进行补充，以书面形式签订补充协议。补充协议与本合同具有同等法律效力。
2、本合同之附件均为合同有效组成部分，具有同等效力。
3、本合同及其附件和补充协议中未规定的事宜，均遵照中华人民共和国有关法律、法规和规章执行。
4、本合同壹式贰份，甲乙双方各执壹份，均具同等法律效力。
5、本合同在履行中如发生争议，双方应协商解决，协商或调节不成的，双方同意由仲裁委员会仲裁。
6、合同期满本合同自然终止。双方如续订合同，应在该合同期满七天前向对方提出书面意见。
7、本合同自双方代表人签字或盖章之日起生效。
甲 方：乙 方：
代表人：(签章)代表人：(签章)
日期：年 月日 日期： 年 月 日
